Chicks in Construction

The Condo Disaster That Left Homeowners Trapped

A construction project intended to expand a local sewer system turned into a nightmare for residents of the Woodland Hills Condominiums in Southgate, Kentucky. After excavation began near the property, residents reported severe foundation cracks, uneven floors, shifting doors, and separating balconies. The damage escalated into a landslide, forcing dozens of residents to leave their homes while continuing to face mortgages, HOA fees, and the cost of finding somewhere else to live. Mikki Paradis and Jessica Abreu break down the timeline, the lawsuits involving the sanitation district, Bray Construction, and other parties, and the financial consequences for homeowners who lost access to their properties. They also discuss the Kentucky Supreme Court's February 2026 ruling that overturned a temporary financial assistance order for eight homeowners, while the larger question of responsibility remains unresolved. This episode explores construction accountability, HOA costs, housing insecurity, and the devastating consequences when homeowners are left paying for damage they did not cause. Have a construction or renovation story to share? Visit ChicksInConstruction.com to tell your story, and follow @ChicksInConstructionPodcast on Facebook, Instagram, and LinkedIn, or @ChicksInConstruction on TikTok. 00:00 Welcome to Chicks in Construction 03:40 Why the hosts are researching this case carefully 04:40 The Southgate condo landslide story 08:00 Background on the Woodland Hills Condominiums 09:30 The sewer expansion project and construction contract 11:00 Foundation damage and warning signs inside the condos 14:30 The landslide and evacuation of residents 16:00 Homeowners displaced while still paying their bills 18:30 Lawsuits, the HOA, and the cost of a retaining wall 22:00 How unpaid HOA fees can put homeownership at risk 23:30 Questions about slope stability and construction oversight 26:00 The financial and personal toll on displaced residents 30:00 Relocation assistance offered to homeowners 31:30 Temporary financial relief and the court challenges 33:00 The Kentucky Supreme Court ruling 34:30 What remains unresolved in the case 36:00 HOA responsibilities and unexpected property costs 38:30 Construction industry criticism and the hosts' social media comments 42:00 Where to follow the show and submit your story

• Transcript

Red Flags When Hiring a Contractor & What a Good Remodel Process Looks Like

Host Mikki Paradis welcomes returning guest Nicole Fella, an interior designer and licensed general contractor who owns Bath Remodeling Center in Cary, North Carolina, specializing in kitchen, bathroom, and walk-in closet renovations. Facebook: https://www.facebook.com/bathremodelingcenter Instagram: https://www.instagram.com/bathremodelingcenter Pinterest: https://www.pinterest.com/bathremodelingcenter/ They discuss social media trolls, why some men rage bait women in construction, and how the show helps homeowners navigate contractors by sharing stories. Mickie and Nicole react to a contractor video that publicly shames a homeowner’s reasonable email about door rough openings, explaining why this behavior is a hiring red flag and how contractors should educate instead. Nicole then walks through her company’s remodeling process: detailed quoting, minimizing allowances, contract specifics, deposit norms, consistent communication, using mostly in-house crews, staging materials before demo, realistic timelines (about 2.5 weeks for baths plus glass; about 5–6 weeks for kitchens), inspection realities, and clarifying that contractors should pay for failed inspections caused by their own work. 00:00 Welcome and Nicole Returns 01:10 First Trolls on Social 02:45 Why the Podcast Exists 06:23 Contractor Shaming Trend 11:09 Red Flags on Social Media 18:23 Nicole’s Remodel Process 22:26 Allowances and Quote Traps 25:36 Contracts Deposits and Subs 31:46 Project Management and Updates 34:06 Inspection Delays Reality 35:31 Durham County Nightmares 38:18 Client Communication Style 39:30 Materials Staged Before Demo 40:03 Granite Templating Timeline 41:36 Avoid Allowances Trap 45:31 Bathroom Remodel Timeframe 49:27 Kitchen Reno Six Weeks 54:14 Contractor Red Flags 55:05 Who Pays Failed Inspections 56:33 Final Takeaways and Wrap

• Transcript

Mold Took Over Their Home: Homeowner Horror Stories

In this episode of Chicks in Construction, Mikki Paradis and Jessica Abreu dive into a homeowner story involving mold, excessive humidity, HVAC problems, poor ventilation, and major construction issues that eventually led to a lawsuit. The homeowner discovered mold appearing throughout the home, including inside cabinets and around areas where water was stagnant. After testing, the source was connected to extremely high humidity and problems with the home's HVAC system. The home was reaching 70 to 80% humidity, the HVAC system was not properly removing moisture, and water was found inside the ductwork. The attic was also poorly ventilated, and the home was not fully weatherized. The repairs quickly became expensive, with estimates reaching $60,000 to $80,000. The story eventually uncovered documents that allegedly showed the previous owners knew about similar problems before selling the home. The homeowners are now involved in litigation and say they have documentation supporting their case. The hosts discuss the importance of inspections, documentation, proper HVAC installation, ventilation, weatherization, and understanding what you are getting into when buying a home. Mikki and Jessica also talk about why they want to hear stories from both homeowners and builders, including situations where homeowners may be contributing to construction problems themselves. If you have a construction story to share, visit chicksinconstruction.com. You can also find Chicks in Construction on TikTok at @chicksinconstruction and on Facebook, Instagram, and LinkedIn at @chicksinconstructionpodcast. 00:00 Welcome to Chicks in Construction 05:00 How this homeowner story began 10:00 Mold found inside the home 12:00 Problems with the shower 16:00 Mold and stagnant water 18:00 HVAC and humidity problems 21:00 The HVAC installation issues 23:00 Poor attic ventilation 25:00 The cost of fixing the home 28:00 Why the homeowners went to court 31:00 Evidence and the legal case 34:00 Health concerns and living with mold 36:00 The homeowner's health improved 38:00 The seller disclosure issue 40:00 Discovering the previous lawsuit 43:00 Evidence in the case 45:00 A possible fight and win story 47:00 How to submit your story

• Transcript

New Home, Hidden Problems: What Homeowners Need to Know

In this episode of Chicks in Construction, Mikki Paradis and Jessica Abreu break down a homeowner dispute involving a new construction home, water intrusion, suspected mold, and questions about the home's construction and waterproofing. The episode follows the homeowner's experience after problems reportedly began within six months of moving into the home. When repeated concerns about water intrusion were met with recommendations to use caulk and reseal grout, the homeowner eventually opened up her own shower to investigate what was happening behind the tile. Mikki and Jessica explain why tile and grout are not the complete waterproofing system in a shower, how water can travel far from its original source, and why simply sealing the visible wet spot may not solve the underlying problem. They also discuss the importance of proper plumbing ventilation, keeping moisture out of attic spaces, and understanding what is behind the finished surfaces of a home. The hosts are careful to point out that the homeowner's lawsuit is still active and that no determination of fault has been made. They also distinguish between the homeowner's reported health concerns and what can actually be established through medical evidence. Along the way, Mikki and Jessica discuss what homeowners should do when they notice recurring water problems, including documenting concerns, getting the right professionals involved, understanding warranty implications, and avoiding unnecessary demolition before understanding the potential consequences. The episode also highlights a larger lesson for homeowners: when something continues to go wrong, do not ignore it just because the visible problem seems small. Ask questions, document what is happening, and make sure the underlying issue is properly investigated. If you have a construction story that could help other homeowners learn from your experience, you can submit it anonymously at chicksinconstruction.com. You can also follow Chicks in Construction on Facebook, LinkedIn, and Instagram at @chicksinconstructionpodcast and on TikTok at @chicksinconstruction. 00:00 Welcome to Chicks in Construction 06:00 The homeowner story and the mysterious builder 08:00 The lawsuit and what happened 12:00 The homeowner takes a hammer to the shower 15:00 Water intrusion and reported health concerns 17:00 Can caulk actually fix a water problem? 20:00 Why homeowners should be careful with demolition 22:00 Understanding shower waterproofing 24:00 Why water finds its own path 26:00 Suspected mold and the inspection 28:00 The plumbing vent problem 31:00 The homeowner's concerns and the builder's response 34:00 How construction problems can stack up

• Transcript

Your New Home Could Be Rotting?!

Mikki Paradise and Jessica Abreu take a closer look at what can go wrong when building or buying a home, including hidden water damage, structural issues, inspections, warranties, and the importance of doing your homework before choosing a builder. The episode explores why passing a building inspection does not necessarily mean a home was built correctly, how rushed construction can lead to major problems, and why homeowners need to understand their rights and responsibilities when something goes wrong. Mikki and Jessica also discuss real cases involving major home builders, construction defects, warranty disputes, and what homeowners can do to better protect themselves. News sources mentioned: • FOX 13 Tampa Bay • Hunterbrook Media and its investigation, The House From Hell 00:00 What Chicks In Construction is all about 07:00 The construction story behind today's episode 13:00 Hidden problems behind your home's walls 18:00 Water intrusion and improperly installed windows 20:00 Who is responsible when something goes wrong? 24:00 Private inspectors and potential conflicts of interest 25:00 What a building inspection actually means 31:00 Construction defect deadlines and homeowner rights 34:00 The House From Hell investigation 40:00 Warranties, delays, and forced arbitration 45:00 What homeowners can learn from these cases 47:00 How to protect yourself when choosing a builder

• Transcript

Navigating the Construction Jungle

In this episode of Chicks in Construction, Mikki Paradise and Jessica Abreu break down one of the wildest homeowner horror stories yet: a Florida custom home builder who collected more than $8.7 million from 15 families while failing to pay subcontractors and suppliers. The homeowners did what most people would consider their due diligence. They hired an established builder, signed contracts, made payments, and waited for their custom homes to be completed. But eventually, the trucks stopped coming. Then the lien notices started arriving. The episode explains how construction draws work, why paying your general contractor does not necessarily mean the subcontractors have been paid, and how unpaid tradespeople can place liens against a homeowner's property. The hosts also explain why unfinished construction can become dramatically more expensive to complete and why homeowners can end up paying twice for work they already paid for. Mikki and Jessica also break down the warning signs homeowners should look for before and during a construction project, including lien waivers, notice letters, payment schedules, large upfront deposits, and third party construction escrow services. Most importantly, they explain what to do if your construction project has already gone wrong. Stop releasing payments, document everything, run a lien search, investigate the builder's history, and contact a construction attorney in your state as quickly as possible. This episode is a reminder that prevention is often the best protection when you're building or remodeling a home. Disclaimer: Mikki and Jessica are not attorneys. Construction lien laws vary by state, and this episode is intended for educational purposes only. Speak with a qualified construction attorney in your state for advice about your specific situation. 00:00 Welcome to Chicks in Construction 02:00 What are Homeowner Horror Stories? 07:00 Disney's senior community in North Carolina 10:00 Why general contractors need construction experience 13:00 The Florida construction story begins 17:00 Imagine saving for years to build your dream home 19:00 How homeowners and subcontractors both get hurt 21:00 Why subcontractors can put liens on a property 22:00 What makes a custom home different from a production home 24:00 How homeowners' money is exposed during construction 27:00 How 15 families were affected 28:00 The three reasons homeowners didn't realize what was happening 30:00 What is a construction draw? 31:00 Why you should never pay ahead of the work 34:00 How construction liens work 38:00 Why finishing an abandoned construction project costs more 40:00 How liens can prevent you from selling or refinancing 41:00 The builder's sentence 42:00 $8.7 million in restitution 47:00 Seven ways to protect yourself 48:00 Lien waivers with every draw 49:00 Don't throw away scary letters 51:00 How much should a construction deposit be? 52:00 The danger of using new deposits to pay old bills 55:00 How to find out how bad the situation really is 56:00 Who should you call first? 57:00 The biggest mistake homeowners make 58:00 The one thing every homeowner needs to remember 59:00 Share your story and follow Chicks in Construction

• Transcript

Sinking Homes in a 55+ Community: Cracks, Soil, Retaining Walls & What Homeowners Must Ask

Host Mikki Paradis, a longtime drywall and paint contractor and licensed North Carolina general contractor, and co-host Jessica Abreu explain the purpose of their Chicks in Construction podcast: sharing construction “shenanigans” and teaching homeowners what’s normal, what’s not, and how to protect themselves. After a personal “chickychat” about Mickey’s severe insomnia and strange social media feeds, they introduce a major construction defect story involving the Del Webb 55+ community developed by Pulte Group outside Las Vegas, where homeowners allege homes are sinking due to issues tied to soil grading and retaining walls. They discuss warning signs beyond typical settling—recurring cracks, separating patios, doors not latching, uneven floors—why homeowners should compare notes with neighbors, and why geotechnical reports, drainage, slopes, and retaining walls matter. They urge asking follow-up questions, documenting everything, and submitting stories at chicksinconstruction.com. 00:00 Meet the Hosts 00:20 Mickey Construction Backstory 03:09 Why This Podcast Exists 05:08 How to Submit Stories 07:06 Jess Homeowner Perspective 07:56 Podcast Style and Chicky Chat 11:12 Sleep Deprivation and Weird Algorithms 19:49 Del Webb Sinking Homes Setup 21:53 Cold Open Retirement Nightmare 24:57 Neighborhood Defects and Red Flags 29:21 Talk to Your Neighbors 30:13 Compare Notes Neighbors 31:21 Settling Versus Movement 33:56 When Cracks Mean Trouble 37:09 Ask Better Followups 40:12 From Facebook To Lawsuits 43:09 Why Soil Matters 46:01 Permits And Soil Tests 49:48 Retaining Wall Red Flags 51:12 Smart Questions Buyers 53:16 Protect Yourself Proactively 56:46 Document And Communicate 01:00:10 Share Stories And Subscribe 01:02:27 Final Wrap And Goodbye

• Transcript

Airbnb Stolen Toilet Brushs & A Moldy House Mystery

Mickey Paradise and co-host Jessica Abreu kick off the episode joking about accidentally matching in white button-up shirts, then dive into the realities of owning short-term rentals, including guests stealing a toilet brush and cutting board, rearranging an Airbnb kitchen, and bringing dogs without permission. Mickey shares a major incident where birthday guests without reviews triggered a noise monitor repeatedly, admitted to having 16 people in a small townhouse, and were ultimately removed through Airbnb after continued violations; afterward, the hosts discovered multiple towels and sheets drenched in blood and some blood on the carpet. The hosts respond to a listener from Washington asking about acting as their own GC and advise using scheduling/permit tracking tools and gaining experience working for a GC first. They close with a Maryland flipped-house nightmare involving floods, mold, sweating ductwork and wood, humidity issues, and ghosted contractors, asking viewers to help diagnose the root cause and directing submissions to chicksinconstruction.com and their social channels. 00:00 White Shirt Twinning 00:42 Short Term Rental Reality 02:16 Stolen Toilet Brush 03:16 Kitchen Organizer Guest 04:53 Noise Monitor Party Bust 09:50 Eviction and Blood Towels 12:28 Book Ideas and Fan Stories 13:27 Cora Builds as GC 16:48 Advice on Permits 18:11 Jobsite HR Reality 18:50 Permits Scheduling Tools 19:44 Get GC Experience First 20:57 Maryland Flip Disaster 23:52 Mold Humidity Clues 25:23 Ghosted By Pros 26:55 Egress Window Chaos 29:49 Root Cause Hunt 31:20 Crowdsource The Fix 32:46 Share Stories Follow 33:52 Wrap Up Goodbye

Medication Mistake Killed My Dog + $80K Kitchen Horror Story (Worcester, MA)

This podcast’s goal is to educate homeowners through submitted “homeowner horror stories.” Mikki shares a personal warning after her English mastiff, Optimus Prime, died from a drug interaction: carprofen and progesterone were prescribed together, leading to a catastrophic GI bleed, and she urges viewers to verify medication interactions and pursue accountability through reporting and complaints. The episode then covers a Massachusetts kitchen remodel disaster: a homeowner hired a contractor from a mailbox flyer, paid half up front without a written contract, faced unlicensed electrical work that failed inspection, erratic scheduling, long disappearances, and ballooning costs, ultimately spending about $80,000 after hiring a licensed company to finish properly and learning to verify licensing, get everything in writing, and protect themselves contractually. 00:00 Welcome and New Setup 00:31 What the Podcast Does 02:22 A Personal Story Begins 03:05 Optimus Prime and Mastiffs 07:35 The Medication Mix-Up 13:18 Aftermath and Accountability 20:28 Transition to Horror Stories 20:57 Worcester and Budget Reality 25:49 COVID Prices and Greed 28:29 Red Flags With the Contractor 29:58 Demo Fast Then Stalls 31:06 Permits Licensing and Chaos 32:33 Wicked Stressed Realization 32:54 Calling the Inspector 33:55 Electrical Work Fails 34:27 Costs Spiral and Disappear 34:58 Contractor Vanishes Six Weeks 35:30 Feeling Lost and Ashamed 36:00 Why Homeowners Don't Know 40:50 Consumer Affairs Game Plan 43:17 Firing the Contractor 43:54 Airbnb Side Quest Chaos 46:51 Hiring a Licensed Remodeler 48:17 Final Bill and Lessons 49:26 How to Vet Contractors 50:52 Facebook Recs Ask for Photos 53:27 Contracts Protect Homeowners 54:42 Wrap Up and Where to Find Us

• Transcript

Dream Home to Construction Nightmare Part 2

In Part 2, Chicks in Construction hosts Mikki Paradis and Jessica Abreu continue examining the ongoing dispute involving Minnesota attorney and content creator Dylan White, known as The Dad Chats, his wife Suzanne, and the builder of their custom home. According to allegations discussed in the lawsuit, the Whites reported recurring drywall cracks, nail pops, floor movement, subfloor deflection, elevated moisture readings, and other concerns they believed went beyond an ordinary new-home punch list. The builder disputes the allegations. But this episode is really about what happened after repeated repairs didn't provide answers. Mikki and Jessica explain why fixing the visible damage isn't the same as fixing its cause. When a drywall crack keeps returning, moisture keeps appearing, or the same problem requires repair after repair, it's time to ask a different question: Why does this keep happening? That's what Dylan and Suzanne reportedly began doing. Instead of relying solely on the builder's warranty process, they brought in independent specialists to investigate specific systems—including flooring and possible water intrusion. The episode explains why homeowners may need a flooring specialist, building-envelope expert, structural engineer, geotechnical engineer, or forensic inspector rather than expecting one person to diagnose everything. According to the lawsuit, the Whites allege that after they began bringing independent experts to the property, individuals associated with the builder appeared when inspections were taking place. The complaint includes allegations that an inspector was photographed or recorded from across the street and that members of the White family were photographed or recorded without their knowledge. These allegations form part of an invasion-of-privacy claim and are disputed by the builder. The episode closes with lessons homeowners can take from the dispute regardless of its eventual outcome: recognize patterns, bring in independent experts when necessary, document recurring problems, keep important communication in writing, and don't confuse repairing damage with identifying its cause. This is an ongoing legal dispute. The claims discussed in this episode are allegations, the builder disputes them, and the court has not made factual findings establishing the allegations discussed. 00:00 – They believed they were being watched 00:35 – Welcome back & Part 1 recap 05:00 – Inside the lawsuit 08:00 – Why recurring repairs matter 09:00 – Moisture & mold concerns 10:30 – Did they fix the cause? 14:00 – Looking for answers 16:30 – Hiring independent experts 19:00 – Moisture testing 20:00 – Why specialists matter 23:00 – Independent experts vs. the builder 26:00 – Don't diagnose your own house 29:00 – The story takes a creepy turn 30:00 – Surveillance allegations 33:00 – Photos of the family 34:30 – Invasion of privacy claim 38:00 – When trust breaks down 40:00 – Document everything 42:30 – Is contractor licensing enough? 45:00 – The single-point-of-failure problem 49:00 – Are homeowners adequately protected? 51:30 – What homeowners should learn 54:00 – Share your construction story

• Transcript

Dream Home to Construction Nightmare

In this episode of Chicks in Construction, Mikki Paradis and Jessica Abreu dig into the ongoing lawsuit involving Minnesota attorney and content creator Dylan White, known online as @TheDadChats, and the builder of his family's custom home. The episode begins with a bigger question: How much experience should someone need before they're trusted to build a house? Mikki and Jessica discuss contractor licensing requirements, why a license doesn't necessarily equal experience, and why homeowners should investigate who's actually building their home. Then they get into Dylan's story. According to allegations discussed in the episode, what initially looked like typical new-home issues—drywall cracks, nail pops, and cosmetic defects—eventually grew into hundreds of reported concerns. Mikki explains why individual problems may be completely normal, but several systems showing recurring problems can warrant a much closer look. Then came the moment that changed everything: Dylan has publicly said his children were playing in a small bounce house in the basement when his wife noticed movement upstairs, including rattling pictures and objects moving on shelves. The hosts discuss why that experience, combined with the other reported issues, raised bigger questions about what was happening with the house. Mikki also breaks down the difference between normal settling and a pattern of potential warning signs. A drywall crack, squeaky floor, sticky door, or nail pop alone may have an innocent explanation. But when multiple systems repeatedly show signs of movement, homeowners should start looking for a common cause rather than treating every symptom separately. Because this litigation is ongoing, the claims discussed in this episode are allegations and have not been established as fact. The builder disputes the homeowners' characterization of the issues. And this story isn't over. Part 2 is coming next. 00:00 – When house movement becomes a red flag 00:45 – Welcome to Chicks in Construction 04:00 – Mikki’s $5,500 vet bill 09:00 – Jess’s dog attack story 12:00 – The contractor debate goes viral 14:00 – Does a GC need experience? 16:30 – Contractor requirements by state 19:00 – States without statewide GC licensing 21:00 – Why experience matters 24:30 – The $1.2 million lawsuit 30:00 – Who is Dylan White? 33:00 – The first problems appear 35:30 – Nearly 500 reported defects 38:30 – Normal settling vs. warning signs 41:00 – Doors, floors & recurring cracks 44:00 – Stop fixing symptoms 46:00 – The bounce house moment 50:00 – How much should a floor move? 52:30 – Multiple problems create a pattern 53:30 – To be continued

• Transcript

Flipped Homes, Hidden Damage & the Truth About "As-Is" Sales

Welcome back to another episode of Chicks in Construction — the true crime podcast, construction edition! This week Mikki and Jessica kick things off with some Chicky Chat: Hector's international gallbladder surgery adventure in El Salvador (complete with translation app fails, gloveless procedures, and Juan Carlos saving the day), plus travel tales from Jess's European cruise. Then it's on to the main story: why the prettiest flipped homes can hide the ugliest secrets. Fresh paint, brand-new floors, and gorgeous quartz countertops can conceal water damage, mold, missing permits, and structural problems that don't show up until months after closing. As always, we're not attorneys or doctors, and this isn't legal advice — but these real cases and lessons can help you avoid becoming one of our future stories. Got a story of your own? Share it with us at chicksinconstruction.com — we'll always keep you anonymous, even if you don't check the box. Follow us: Facebook, LinkedIn & Instagram: @chicksinconstructionpodcast TikTok: @chicksinconstruction #ChicksInConstruction #HomeBuying #HouseFlipping #RealEstate #TrueCrimePodcast #HomeInspection #RenovationRedFlags Chapters: 0:00 Intro & Chicky Chat (Hector's El Salvador surgery, Jess's cruise) 27:03 Getting to today's story 27:17 The dream home that's hiding secrets 29:50 The bidding war & waived inspections 36:48 Johnson v. Davis and seller disclosure law 41:41 When the inspector misses it 45:58 "As-is" doesn't mean anything goes 57:12 Rapid-fire red flags to watch for 1:01:59 Where to find us Submit your homeowner horror story: www.chicksinconstruction.com Follow on Social Media: www.instagram.com/chicksinconstructionpodcast www.facebook.com/chicksinconstructionpodcast www.linkedin.com/company/chicksinconstructionpodcast www.youtube.com/@ChicksInConstruction ________________ Love what you hear? Subscribe to Chicks in Construction and share this episode with your friends because every homeowner, builder, contractor, and designer needs to hear this one!

• Transcript

What Homeowners Insurance Actually Covers

In this episode of Chicks in Construction, Mikki Paradis and Jessica Abreu explain what homeowners insurance actually covers, why construction defects and long-term water intrusion are frequently excluded, and how homeowners can protect themselves before something goes wrong. They also discuss the surprisingly low barrier to becoming a licensed general contractor, the difference between a home inspector and a building inspector, and why a contractor can be responsible for an entire home without completing the apprenticeship or experience requirements expected in many individual trades. Through real court disputes, homeowner stories, and firsthand experiences, Mikki and Jessica explain why insurance is not a home warranty, contractor warranty, or maintenance plan—and why identifying the cause of damage is often more important than proving the damage exists. You’ll also learn what documents to save, when filing a claim may increase your future costs, what to do after a denial, and why hiring the cheapest contractor can become the most expensive decision you ever make. 00:00 – General contractor licensing 00:45 – New podcast setup 02:00 – European vacation recap 03:00 – Gluten-free travel in Italy 05:00 – Six countries in one trip 07:00 – Venice: worth the visit? 10:45 – Viral builder lawsuit 14:00 – How easy is contractor licensing? 16:00 – Home vs. building inspectors 18:00 – Social media backlash 21:00 – Homeowner horror stories 26:00 – What insurance really covers 28:00 – The burned fence claim 29:30 – Stolen car insurance story 32:00 – Why claims raise your rates 33:30 – Insurance is not a warranty 34:30 – Challenging a denied claim 37:00 – Hidden water damage 38:00 – Find the leak first 40:00 – What caused the damage? 41:30 – Documents homeowners should save 43:00 – Roof damage vs. normal wear 45:00 – When filing a claim makes sense 46:30 – Faulty workmanship exclusions 49:00 – The cheapest contractor trap 50:00 – How to verify a contractor 51:00 – Understanding your policy 52:00 – Documenting your belongings 53:00 – What to do after a denial 54:00 – Public adjusters and experts 55:00 – Final homeowner advice

• Transcript

What Every Homeowner Should Know About Plumbing

Main Street Plumbing Company: https://mainstplumbingnc.com/ Main Street Plumbing Number: 919-617-0496 Capps Plumbing Company: https://cappsplg.com/ In this episode of Chicks in Construction, Mikki Paradise welcomes Hailey, a plumber with more than 14 years of experience, to share hilarious stories, hard-earned lessons, and practical advice every homeowner should know. From the strangest things ever flushed down toilets to why plumbers cringe when they hear someone used Drano, Hailey explains the mistakes that lead to expensive repairs—and how homeowners can avoid them. The conversation also explores what it's like being a woman in the plumbing trade, dealing with stereotypes, earning respect on the job, and why the construction industry needs more women. Along the way, Mikki and Hailey discuss water heaters, water pressure, plumbing maintenance, DIY repairs, builder shortcuts, and the importance of finding a plumber you can trust. Whether you're a homeowner trying to prevent costly repairs or someone considering a career in the skilled trades, this episode is packed with practical advice, laughs, and insider knowledge. 00:00 – Welcome back to Chicks in Construction 01:00 – Meet guest plumber Hailey 04:00 – How Hailey became a plumber 06:30 – Why the trades were a better fit than college 07:00 – What it's like being a woman in plumbing 10:00 – Why construction should be called "male-populated," not "male-dominated" 11:30 – Homeowner mistakes plumbers see every day 14:00 – Why plumbers hate Drano and drain cleaners 17:00 – The only three things that belong in a toilet 18:00 – Flushable wipes aren't really flushable 19:00 – Grease, clogged drains, and expensive repairs 20:00 – The strangest things ever flushed down a toilet 23:00 – Inside Main Street Plumbing 26:00 – Why water pressure matters 28:00 – Knowing where your main water shutoff is 30:00 – Water damage prevention every homeowner should know 33:00 – Should you flush your water heater? 35:00 – Plumbing maintenance plans explained 37:00 – Extending the life of your water heater 38:00 – Warning signs your water heater is failing 39:00 – Why you should shut your water off before vacation 42:00 – Cheap toilets vs. quality plumbing fixtures 45:00 – Why trustworthy contractors are worth keeping 50:00 – Builder shortcuts plumbers see every day 53:00 – Which plumbing repairs are safe to DIY? 55:00 – Final homeowner tips

• Transcript

Contractor Catastrophes: What Every Homeowner Should Know

In this episode of Chicks in Construction, hosts Mikki Paradis and Jessica Abreu discuss an Arizona case in which senior citizens Elizabeth Matthews and her husband hired Settlers West Home Builder in May 2022 to build a $1M custom home in Tucson’s Catalina Foothills, then were persuaded to sign a separate $300,000 guest-house contract and pay large amounts in cash outside their construction loan. After paying $150,000 for the main project plus $150,000 and later $105,000 toward the guest house (and nearly $60,000 in upgrades), the couple saw major delays, received no refund when requested, and ultimately learned the builder filed for bankruptcy in December 2023, leaving two homes only framed. The builders had 18 license complaints before revocation in February 2024. The hosts stress red flags, not paying for uncompleted work, milestone-based draws, lien waivers, and retainage. 00:00 Renovation Limbo Warning 00:25 Podcast Intro and Horror Stories 02:47 Why Contractors Dodge Consequences 09:04 Time Optimist Tangent 13:45 Hoarding vs Throwing Away 19:01 Deep Dive Redemption Setup 20:34 Dream Home Disaster Begins 22:59 Meet the Matthews and the Contract 26:08 Guest House Upsell Red Flags 27:53 Discounts as Red Flags 28:42 Cash Pressure and Markups 31:02 Selling the House to Pay 32:54 Delays and Sunk Cost Trap 36:34 Overpaying for Bare Framing 38:38 Complaints and Bankruptcy Twist 48:13 Why Fixing Work Costs More 52:39 Pay Milestones and Lien Waivers 56:43 Retainage and Final Takeaways

• Transcript

The House That Shouldn’t Have Been Demolished

Mikki Paradis and co-host Jessica Abreu introduce the Chicks in Construction podcast, explaining their mission to help homeowners understand what’s normal, spot red flags, and avoid contractor scams by sharing “Homeowner Horror Stories” submitted at chicksinconstruction.com. They discuss how construction failures often come from chained mistakes and share a shocking Atlanta, Georgia incident where a private demolition crew tore down the wrong inherited family home while the owner was on vacation, then left; the City of Atlanta issued a correction notice requiring the owner to clean up rubble and warning of fines despite the work being unpermitted and unauthorized. They note similar Atlanta cases, compare homeowner protections across states, and invite listeners to submit stories and follow the show on social media. 00:00 Cold Open Banter 00:20 Podcast Mission 03:14 Submitting Horror Stories 05:16 Cups Hydration Heat 05:54 NC Weather Whiplash 07:44 Running Zombies Alaska 12:51 Neighborhood Demo Problem 15:40 Why Trees Matter 16:33 House Shouldnt Demolish 18:13 Wrong House Shock 19:51 How Crews Miss Addresses 21:02 Drywall Wrong House Story 23:16 Safeguards That Failed 23:48 Irreplaceable Memories Lost 25:59 Contractor City Fallout 29:04 Atlanta Pattern Of Demos 35:13 Homeowner Protections Gap 39:22 Share Your Story Outro

• Transcript

Contractor Collapse: How Homeowners Can Protect Themselves

On this episode of The Chicks in Construction, hosts Mikki Paradis and Jessica Abreu discuss how scammers exploit stress and access to personal information, including a story of a woman in the Raleigh area who was tricked by a caller ID–spoofed “Wake County Sheriff’s Office” into paying $4,000 to “buy out” a fake warrant. They explain why law enforcement doesn’t collect payments over the phone and advise hanging up and calling the non-emergency number directly. The conversation then shifts to an Arizona luxury pool contractor situation where homeowners paid large deposits for $80,000–$200,000 backyard projects that stalled, leaving unsafe excavation pits and unfinished work. They outline red flags like massive upfront deposits, loss of momentum, vague delays, and misleading social media, and recommend protections such as milestone-based payments, verifying suppliers, checking licensing/standing, and cutting losses early. 00:00 Contractor Scam Reality Check 00:31 Meet The Hosts And Mission 01:27 Jury Duty Sheriff Scam 04:37 Dark Web And Number Cloning 09:04 How The Scam Extracts Money 12:40 Aftermath And Safety Tips 20:22 Share Your Horror Stories 21:51 Arizona Luxury Pool Nightmare 25:52 Deposits Paid Then The Collapse 27:43 Pool Build Nightmare 28:43 Cashflow Collapse Explained 30:44 Upfront Deposit Red Flags 33:15 Permits Inspections Pushback 37:06 Branding Can Be Fake 40:06 Momentum Stalls and Demo Trap 45:17 No Crew Means No Pay 48:05 Protect Yourself With Milestones 51:43 References Research and Reality 56:09 Final Lessons and Call In

• Transcript

Nailed It? The Hard Truth About Home Makeovers

In this episode of Chicks in Construction, Mikki and Jessica unpack another homeowner renovation nightmare — this time from Florida — involving an unlicensed contractor, endless delays, disappearing cabinets, surprise costs, and complete chaos inside a family home for nearly eight months. What started as an exciting kitchen renovation quickly spiraled into stress, financial anxiety, strangers showing up unannounced, and a growing realization that the contractor they trusted was never legitimate in the first place. Along the way, Mikki and Jessica go on several hilarious side quests involving jury duty scams, true crime energy, sketchy contractors, and why homeowners must verify licenses, insurance, permits, and registrations before any renovation begins. The episode is equal parts comedy, cautionary tale, and practical education for homeowners trying to avoid becoming the next construction horror story. 00:00 – The emotional reality of living through a renovation nightmare 00:45 – What Chicks in Construction is all about for new listeners 02:00 – Why shady contractors get angry when homeowners ask for permits 03:00 – Mikki’s “particular set of skills” rant begins 05:00 – Jury duty scams and fake warrants explained 08:00 – Mikki gets an actual jury summons and is way too excited about it 11:00 – Jessica explains how she got dismissed from jury duty instantly 12:00 – The insane burglar lawsuit story 15:00 – Bartending, over-serving, and legal liability stories 18:00 – Why listeners should keep submitting homeowner horror stories 20:00 – Callie the “non-consensual licker” dog side quest 23:00 – Today’s homeowner horror story begins: the Florida kitchen renovation 26:00 – “We thought we were doing something exciting for our family.” 30:00 – The contractor confidently claims he’s licensed 32:00 – The kitchen demolition begins and everything falls apart 33:00 – The homeowner discovers the cabinets were never ordered on time 35:00 – Delays, missing materials, and mounting frustration 36:00 – Random workers begin showing up without warning 38:00 – Why homeowners need communication and safety protocols during renovations 40:00 – The renovation budget spirals out of control 41:00 – Eight months without a functioning kitchen 42:00 – The homeowner discovers the contractor was never licensed 44:00 – Mikki explains why shady contractors hate permit conversations 45:00 – Why homeowners must independently verify licenses and insurance 48:00 – The hosts discuss possible delay scams and hidden costs 49:00 – Liquidated damages explained in large construction projects 51:00 – Why legitimate contractors don’t profit from delays 52:00 – Insurance verification and contractor credential checks 53:00 – The dangers of renovations completed without permits 54:00 – Why unpermitted work can hurt your home’s resale value 55:00 – Final lessons for homeowners before starting renovations

• Transcript

Urgency, Fear, and Fraud: How to Spot a Shady Contractor

Hosts Mikki Paradis and Jessica Abreu discuss Bay Area reports of groups posing as contractors who target homeowners—especially elderly people—by showing up unsolicited, claiming urgent dangers like failing roofs or unsafe chimneys, and using fear to force quick decisions. They describe how scams often start with small quotes that rapidly escalate into tens or hundreds of thousands of dollars, including one reported $450,000 loss, and note these groups may operate across counties and states under frequently changing business names. The episode highlights red flags such as high-pressure urgency, shifting company identities, and sudden cost increases, and offers protections: never sign the same day, get multiple opinions/inspections, verify licenses and business registration via the Secretary of State, check addresses and phone numbers, and research local permit/inspection requirements. They invite viewers to submit stories at chicksinconstruction.com and share where to follow the podcast on social media. 00:00 Contractor Scam Cold Open 00:28 Meet the Hosts 02:04 Spicy Comments and Rage Bait 04:25 Inspection Rework Rule 08:23 Blocking Trolls and Staying Busy 10:41 Rental Setup Chaos 13:48 Special Trash Trim Haul 17:49 Send Us Your Stories 19:44 Traveling Contractor Scams 20:51 Door Knock Panic Pitch 23:57 Bay Area Scam Details 26:09 Scammers Look the Part 26:37 Fear Based Pitch 27:48 Pressure Sales Red Flags 30:22 Elderly Targeted Scam 32:26 Costs Spiral Fast 34:32 Rotating Company Names 37:13 Door to Door Reality 39:03 Verify People Not Brands 42:50 Organized Scam Networks 45:18 Common Red Flags List 50:16 Protect Yourself Checklist 53:30 Wrap Up And Share

• Transcript

Remodel Horror Stories & Contractor Secrets with  Erika Zimandy

In this episode of Chicks in Construction, Mikki and Jessica sit down with licensed general contractor and real estate investor Erika Zimandy of Hilltop GC for an honest conversation about what homeowners really need to know before hiring a contractor. Erika shares her journey from public health into real estate investing and construction, offering a unique perspective from both sides of the renovation world — as both a homeowner/investor and a licensed GC. Together, they unpack contractor red flags, remodeling horror stories, pricing differences between bids, realistic timelines, deposits, permits, inspections, and the biggest myths HGTV has taught homeowners. The episode also dives into the controversial topic of contractors charging homeowners for failed inspections, whether homeowners should buy their own materials, and what upgrades actually provide the best return on investment. If you’re planning a remodel or simply want to avoid expensive construction mistakes, this episode is packed with practical advice and real talk from women working in the construction industry. 00:00 – Introduction to Erika Salgado-Zemandi from Hilltop GC 02:00 – Facebook contractor stories & homeowner horror stories 05:00 – Erika’s background in masonry, public health & real estate investing 07:00 – Starting Hilltop GC and becoming a licensed general contractor 09:00 – How homeowners can identify trustworthy contractors 10:30 – Why contractors using “big construction words” can be a red flag 12:00 – Green flags homeowners should look for when hiring a GC 14:00 – License lending and why it’s dangerous 15:00 – Biggest contractor red flags & overpromising timelines 16:00 – How many contractor bids homeowners should get 17:00 – Why contractor quotes can vary wildly in price 20:00 – Insurance, taxes & overhead: what homeowners forget about pricing 21:00 – Hidden remodeling surprises behind walls 22:00 – The controversial topic of charging homeowners for failed inspections 24:00 – What happens when homeowners request non-code-compliant work 27:00 – Realistic timelines for kitchens, bathrooms & additions 30:00 – Contractor deposits and payment schedules explained 34:00 – Should homeowners buy their own materials? 38:00 – Best remodeling upgrades for return on investment 40:00 – Kitchen upgrades buyers notice immediately 41:00 – Bathroom trends: tubs vs. giant showers 43:00 – What homeowners overspend on during remodels 47:00 – Craziest requests Erika has received as a contractor 49:00 – Biggest HGTV myths homeowners still believe 52:00 – The truth about staged HGTV renovations and furniture reveals

• Transcript